Road Markings Government Bids & RFPs

Payment will be made within thirty 30 days after satisfactory acceptance by the county of all completed services and receipt of a valid invoice, in accordance with the texas governmentcode, chapter **** will be made within thirty 30 days after satisfactory acceptance by thecounty of all completed services and receipt of a valid invoice

Criteria utilized by guadalupe county for determining the lowest responsible bidder includes, but is not limited to, bidder meeting the countys published specifications, biddersexperience, skill, ability, business judgment, financial capacity, possession of the necessary facilities orequipment, previous performance, reputation, promptness, and any factor which could reasonably beasserted as being relevant to successful performance. criteria utilized by guadalupe county for determining the lowest responsible bidder includes, but is not limited to, bidder meeting the countys published specifications, biddersexperience, skill, ability, business judgment, financial capacity, possession of the necessary facilities orequipment, previous performance, reputation, promptness, and any factor which could reasonably beasserted as being relevant to successful performance.

To be considered for this purchase, your firm must meet the qualifications and satisfy the requirements set forth in the ifb. to be considered for this purchase, your firm must meet the qualifications and satisfy the requirements set forth in the ifb.

Liquidated damages for delay in completion are five hundred dollars **** per calendar day. liquidated damages of five hundred dollars **** per calendar day in the event of its failure to complete work inaccordance with the schedule set forth in the agreement.

Any sample with percent air voids of more than 10 or less than 2 will be rejected. any sample with percent air voids of more than 10 or less than 2 will be rejected.

Protests before award must be submitted in writing to the purchasing agent not later than six 6 calendar days after bid opening. protests before award must be submitted in writing to the purchasing agent notlater than six 6 calendar days after bid opening,

Incomplete bid submissions all requested required documents signatures will be considered nonresponsive and will be rejected. incomplete bid submissions all requestedrequireddocumentssignatures will be considered nonresponsive and will be rejected.

The contract period is for one year effective the date commissioners courtawards the contract. the contract period is for one year effective the date commissioners courtawards the contract.

The engineers estimate for the project base is seven hundred eighty thousand dollars: The engineers estimate for the project base is seven hundred eighty thousand dollars780, 000.

The response deadline is **** 04:00 pm ct. response deadline: **** 04:00 pm ct

All invoices to the city of laredo have a 30day term from receipt of completion of services. all invoices to the city of laredo have a 30day term from receipt of completion of services.

The selection and award shall be based on the basis of being the lowest responsive responsible bidder, demonstrated competence and qualifications to perform the services. the selection and award shall be based on the basis of being the lowest responsive responsible bidder, demonstrated competence and qualifications to perform the services.

Bidders must submit several required forms, including a bidder information questionnaire, conflict of interest disclosure, noncollusive affidavit, and discretionary contracts disclosure. tab a bidder information questionnaire. pdf this form shall be submitted by all firms or entityies seeking a contract with the city of laredo.

A prebid conference will be held on tuesday, august 25, 2026, at 10:00 a. m. at the city of laredo engineering department city hall 2nd floor, laredo, texas **** prebid conference with prospective bidders will be held on tuesday, august 25, 2026, at 10:00 a. m. at the city of laredo engineering department city hall 2nd floor, laredo, texas ****.

A request for information shall be made in writing through question response section on citebid system no later than the question deadline date. a request for information shall be made in writing through question response section on citebid system no later than the question deadline date.

Bidders must warrant that they will not engage in employment practices such as discriminating against employees because of race, color, sex, creed, or national origin. no rfb submitted herein shall be considered unless the bidder warrants that, upon execution of a contract with the city of laredo, bidder will not engage in employment practices such as discriminating against employees because of race, color, sex, creed, or national origin.