Latest US Erosion Blanket Contracts & Bids

Sealed bids will be received at 66 Thillen Dr. until October 3, 2025, at 11:00 AM CST. Bids must be submitted on the provided form, including all required information and certifications. The Village of Fox Lake reserves the right to cancel the invitation, accept or reject any or all bids, or to accept an alternate bid. The bidder must self-perform a minimum of 51% of the total project workload. Additional documents required: bidder invitation and bid form, price sheets, worksheet by trade, general information form, bidder qualification form, references form, addendum acknowledgement form, responsible bidder affidavit, bid security, and value engineering proposal (optional). Questions must be submitted by September 22, 2025, via email to ***@***. *. * must be completed by November 21, 2025. Liquidated damages may be imposed for delays past the substantial completion date.

Bid documents must be emailed to ***@***. *. * must comply with Missouri's MBE/WBE/SDVE participation goals. A bid bond or cashier's check for 5% of the base bid is required. The project completion time is 140 working days from the notice of intent to award, plus 10 days for document processing. Liquidated damages of $700 per working day apply for delays beyond the completion time. Various attachments are required, including unit prices, proposed subcontractors, MBE/WBE/SDVE compliance forms, and certifications. Bidders must certify that their bid is genuine, not collusive, and based on accurate contract documents. The bidder must comply with Missouri prevailing wage law, the Davis-Bacon Act, transient employer provisions, federal work authorization program, illegal immigration reform, and antidiscrimination against Israel Act. The bidder must also complete and submit the required forms for subcontractors, MBE/WBE/SDVE compliance, and certifications.

Sealed bids for the construction of Ofallon Family Sports Park North Parking and Lighting are due September 3, 2025, at 8:30 AM at the Ofallon City Hall Clerk's Office. Bidders must be prequalified with the Illinois Department of Transportation. A 5% bid bond, certified check, or cashier's check is required. The successful bidder will be required to furnish a satisfactory performance bond. No bid withdrawals are allowed for 30 days after the opening. The City reserves the right to reject any or all bids. Bidders may obtain bidding documents from the city of ofallon website. Questions about the project may be directed to city parks and recreation. The contractor agrees to commence work within 15 days after execution of the contract, and shall substantially complete the project by November 22, 2024. A mandatory preconstruction meeting will be scheduled within one week of contract ratification. Weekly progress meetings will be held. All invoice submitted for payment shall be paid net **** of the payment due to the contractor shall be retained until the project is successfully completed and all punch list items are adequately addressed. The location of underground facilities is approximate. The contractor is responsible for determining the existence and location of all underground facilities and protecting them from damage. The contractor shall obtain all necessary trade permits from the city of ofallon. The contractor shall guarantee all work for a period of one year from the date of final acceptance and final payment. The contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the work. The contractor shall comply with all applicable laws and regulations of any public body having jurisdiction for the safety of persons and property. No less than the prevailing rate of wages, as determined in accordance with the Illinois prevailing wage act, shall be paid to all laborers, operators, teamsters, masons, plumbers, and any workmen employed in construction on this project. The contractor shall submit payrolls electronically through the certified transcript of payroll portal. The contractor shall maintain and protect all existing facilities, both onsite and offsite. All materials for disposal shall be removed from the site and properly disposed of at locations provided by the contractor. The contractor shall obtain a hydrant meter from the city engineering office should the contractor intend on using water from a fire hydrant within the city of ofallon water system. Failure to comply with any provisions of this storm water pollution prevention plan will result in the implementation of a national pollutant discharge elimination system erosion and sediment control deficiency deduction against the contractor and/or penalties under the permit ilr10.

The solicitation amendment **** for project **** Erfo Road Repairs in the Angeles National Forest is for replacement page 5 and 6. The schedule of items includes mobilization, excavation, rip rap, reclamation, asphalt, drainage, and erosion control. Quantities are estimated, and contractors must verify field requirements. One award will be made. A bid bond/guarantee is required for proposals exceeding $150,000. A site visit is scheduled for July 21, 2025, at **** am hours PDT. Detailed instructions for proposal submission are in section L, paragraph L. 2, on page 34. RFIs must be submitted to the contract specialist, Tanya Torres, on the attached RFI form no later than **** am hours PDT, August 1st, 2025. Failure to inspect the site does not constitute grounds for a claim after contract award. The project is between $250,000 and $500,000, with a total small business set aside.

The Texas Parks and Wildlife Department (TPWD) is seeking proposals for blanket contracts for disaster and FEMA grant administration services. The initial contract term is three years, with a possible renewal for up to two additional one-year periods. Minimum qualifications include five years of experience in grant administration and disaster consulting services, specific FEMA grant experience, and the necessary personnel, skills, facilities, and equipment. Proposals are due August 21, 2025, at 2:00 PM CT. Respondents must submit exhibits including company profiles, key personnel, past projects, and a technical proposal. TPWD will evaluate proposals based on experience, location, availability, and low bid for individual projects. Additional product/service requests may be made after contract award.