Floor Removal Government Bids & RFPs

Proposals must be received by email to luke diede at ***@***. *. * by 3:00pm on december 3rd, 2026. proposals must be received by email to luke diede at ***@***. *. * by 3:00pm on december 3rd, 2026.

Contractors must provide a written workmanship and product warranty. ability to provide references for similar projects and a written workmanship and product warranty.

Evaluation considers experience, technical approach, dust containment, schedule, waste management, storage plan, and total proposed cost, clarity of the pricing summary, product and service details, warranty, and overall value.

Contractors must have demonstrated experience resurfacing public, commercial, or comparable aquatic facilities using diamond brite exposed aggregate finishes and hydroblasting preparation methods.

A mandatory site walkthrough will be held on november 17th, at 1:00pm at the berthoud recreation center. a mandatory site walkthrough will be held on november 17th, at 1:00pm at the berthoud recreation center.

First round of questions must be submitted by november 12. first round of questions must be submitted by november 12.

All bids must be received by the deadline; the town is not responsible for delivery delays. all bids must be received by this deadline. the town is not responsible for delivery delays.

For violation of the restriction of communication, the authority reserves the right to reject the submittal of the offending respondent. for violation of this restriction, the authority reserves the right to reject the submittal of the offending respondent.

Bids are due no later than 2:00 p. m. Pacific Time, November 5, 2026. bids shall be due no later than 2: 00 p. m. pacific time, november 5, 2026.

Contractor must provide a one-year workmanship warranty and manufacturers standard warranty on materials. contractor shall provide 1 one year workmanship warranty, and manufacturers standard warranty on materials.

The contract will be awarded to the low responsible bidder. shall award the contract for construction to the low responsible bidder.

An Idaho public works contractors license is required at the time of bid submission. an idaho public works contractors license is required at the time of submitting a bid for this project.

Liquidated damages of $500 per day for late completion. pay as liquidated damages, the sum of 500 five hundred dollars for each consecutive calendar day after the established substantial completion date.

Pre-bid walkthrough is scheduled for October 29 at 10:00 AM, attendance is not mandatory. attendance is not mandatory, however, this is the time allotted for prospective bidders to take measurements.

Substitution requests must be submitted by October 30, 2026, 5:00 PM. substitution requests shall be submitted by the prospective bidders to the lc state contact listed above no later than 5: 00 p. m. on october 30, 2026.

Incomplete bid forms will be deemed nonresponsive. Incomplete bid forms will be deemed nonresponsive.

The selection process will evaluate factors such as design narrative, management plan, schedule narrative, and price, with all evaluation factors, other than cost or price, are considered approximately equal to cost or price.

Offerors must have active SAM registration: offerors shall have and shall maintain an active registration in the SAM database.

If not registered in SAM at award, the government reserves the right to award to the next prospective offeror.

The estimated construction magnitude is anticipated to be between 10,000,000 and 25,000,000 dollars.